gavel sanctuary cities

Massachusetts Appeals Court Ruling: Contractor Justified Not Paying Subcontractor That Refused To Perform Work

Advertisement

The general contractor on a public demolition project paid nothing to a subcontractor that had performed the majority of its work but refused to perform work that it claimed was outside of its scope of work. The subcontractor sued the general contractor and after cross-motions for summary judgment the Superior Court sided with the general contractor, holding that the work in dispute was within the subcontractor’s scope and that the subcontractor breached the subcontract by refusing to perform the work. The Superior Court also held that the subcontractor was not entitled to be paid for the work it did perform because it had not substantially performed its obligations under the subcontract. The subcontractor appealed, and the Massachusetts Appeals Court affirmed the Superior Court’s decision. Acme Abatement Contractor, Inc. v. S&R Corporation, No. 2014-P-257, 2015 Mass. App. Unpub. LEXIS 855 (Aug. 20, 2015). Click here to view the Appeals Court decision.

Contracting Background

S&R Corp. (“S&R”) was awarded a demolition contract by the Town of Weymouth (the “Town”). Part of S&R’s work included the demolition of concrete bleachers adjacent to an athletic field. S&R subcontracted the asbestos abatement work to Acme Abatement Contractor, Inc. (“Acme”). Among other things, Acme was required to remove asbestos containing paint from the bleachers prior to demolition.

Advertisement

Scope Dispute Arises

After Acme had commenced work, it informed S&R that it would remove paint only from the side walls of the bleachers but not the risers because Acme believed that paint did not contain asbestos and, therefore, was not within its scope. S&R directed Acme to the project specifications and identified the contract language that it believed clearly required Acme to remove the riser paint. Despite this language, Acme claimed it did not have to remove the riser paint and even went so far as to have the riser paint tested, which test results came back negative for asbestos. Even though tests performed after the subcontract was signed and work had commenced showed that the riser paint did not contain asbestos, the subcontract language included the risers within Acme’s scope and Acme “owned” that work. Nevertheless, Acme refused to remove the riser paint.

Acme performed the remainder of its obligations and then abandoned the project without removing the riser paint. S&R was forced to engage a substitute contractor to remove the riser paint because the project schedule was in jeopardy and S&R faced the prospect of being assessed liquidated damages by the Town if it did not complete the project on time. S&R did not issue payment for any of Acme’s work, even the two-thirds of the subcontract work that Acme performed, on the ground that Acme had materially breached its subcontract.

Advertisement

Subcontractor Sues and Contractor Wins Summary Judgment

Acme brought suit against S&R seeking $145,000 in damages for breach of contract and quantum meruit. Acme also sought treble damages and attorneys’ fees under M.G.L. c. 93A, for a total of damages in excess of $450,000. Both parties eventually moved for summary judgment. The Superior Court granted summary judgment in S&R’s favor finding that: (1) the subcontract required the removal of the riser paint; (2) the subcontract required that Acme perform the disputed work under protest and that Acme’s failure to do so was a material breach of the subcontract; (3) Acme had failed to provide required closeout documents; and, (4) Acme could not recover under quantum meruit for the work it did perform because it did not substantially complete its subcontract obligations.

Advertisement

Subcontractor Appeals

Acme appealed to the Massachusetts Appeals Court, which affirmed the Superior Court’s decision in S&R’s favor. Rather than address whether the removal of the riser paint was within Acme’s scope, the Appeals Court held that Acme breached the subcontract by not performing the disputed work as required by the subcontract. The relevant language provided:

Click here to continue reading…

© Copyright 2015 Murtha Cullina

Published by

National Law Forum

A group of in-house attorneys developed the National Law Review on-line edition to create an easy to use resource to capture legal trends and news as they first start to emerge. We were looking for a better way to organize, vet and easily retrieve all the updates that were being sent to us on a daily basis.In the process, we’ve become one of the highest volume business law websites in the U.S. Today, the National Law Review’s seasoned editors screen and classify breaking news and analysis authored by recognized legal professionals and our own journalists. There is no log in to access the database and new articles are added hourly. The National Law Review revolutionized legal publication in 1888 and this cutting-edge tradition continues today.